Terms & Conditions

Last updated: 30 September 2025

These Terms govern your use of the website of Mahamaya Construction Pvt. Ltd. (“Company”, “we”, “us”, “our”). By accessing or using this site, you agree to these Terms.

1) Use of Website

Content is for general information only and may change without notice.
Do not misuse the site, attempt unauthorized access, or harm functionality.

2) Services & Quotes

Any proposal, estimate, BoQ, or timeline shown on the site is indicative, not a binding offer.
Final scope, price, and timeline are defined only in the executed Work Order/Contract.

3) Payments

Payment terms, milestones, taxes, and retention are as per the signed Contract.
Late payments may attract interest and suspension of work.

4) Client Responsibilities

Provide timely decisions, site access, approvals, drawings, and utilities as applicable.
Delays caused by the client or third parties extend our timelines accordingly.

5) Changes & Variations

Scope changes must be documented and may adjust cost and schedule.
Price escalations due to statutory changes or market shocks may be passed through as per Contract.

6) Intellectual Property

All designs, drawings, methods, and content on the site belong to us or our licensors.
No reproduction or reuse without prior written consent.

7) Third-Party Links

External links are for convenience. We do not endorse or control third-party sites.

8) Privacy

Use of the site is subject to our Privacy Policy. By using the site, you consent to it.

9) No Warranties (Website)

The site is provided “as is”. We do not guarantee accuracy, completeness, or availability.

10) Limitation of Liability

To the maximum extent permitted by law, we are not liable for indirect, incidental, or consequential damages arising from site use.
For contracted works, liability is limited as stated in the signed Contract.

11) Indemnity

You agree to indemnify us for losses arising from your misuse of the site or breach of these Terms.

12) Force Majeure

We are not liable for delays or failures due to events beyond reasonable control (e.g., natural disasters, strikes, acts of government, pandemics, supply disruptions).

13) Suspension / Termination

We may suspend or terminate site access at our discretion for security or compliance reasons.

14) Governing Law & Dispute Resolution

These Terms are governed by the laws of India.
For project disputes, the executed Contract terms (including arbitration, if any) prevail.

15) Updates

We may update these Terms at any time by posting a revised version. Continued use means acceptance.

16) Contact

Mahamaya Construction Pvt. Ltd.

Registered Address: S-108-09, 1st floor, Sunsqure Shopping Complex, Hill Top Road Near- RIICO Chowk, Bhiwadi

GSTIN: [Insert]

Email: mahamayaconstruction11@gmail.com

Phone: (+91) 823 35 25320, 734 06 25320